Essential law: Variations - Part one
In the first of a series on the basics of construction law, James Worthington and Vanessa Jones begin with variations, considering here the scope of the right to instruct variations.
The variations regime is fundamental to both parties to a construction contract. It gives the employer the flexibility to change the works, and determines the extent to which the contractor will be allowed additional time and money for such changes.
This article will look at some of the issues regarding the extent of the employer’s right to instruct a variation and the contractor’s right to claim that an employer’s instruction is a variation.
What is a variation?
Most construction contracts will include a definition of what is a “variation” under that contract. In general terms, a variation is an instruction by the employer to alter the works to be performed or an instruction to vary their timing, method or sequence.
However, not all instructions will be treated as variations. In particular:
- Where the instructed work is “indispensably necessary” to complete the contract works, the court will generally infer that it is included in the contracted works, regardless of the fact that it is not expressly identified in the specification.
- Where the contractor has agreed to design and build a facility to meet certain performance specifications, changes to the design required to meet those performance specifications will generally not be a variation.
- Where the contractor has taken on a risk under the contract (such as ground conditions), any delay or additional cost that arises from that risk will be the responsibility of the contractor, and will generally not be a variation even though the methodology required to complete the works may have changed.
- Where the contract gives the architect the power to determine the method by which the works are executed, it is generally not a variation if the architect chooses a specific methodology, even if that choice was unreasonable.
Can an employer instruct any variation?
There are certain limits on the employer’s right to instruct a variation that will generally be implied into a construction contract, such that the following are not permitted (unless expressly permitted by the contract or agreed by the contractor):
- Instructions that fundamentally change the nature of the contract, or were clearly not contemplated by the original contract. The guiding principle is that after such variation the works should still be capable of being identified as the works originally defined in the contract.
- Instructions that omit works for the purpose of awarding those works to another contractor. If an employer intends to omit work, it should be for the purpose of omitting that work entirely from the project. The courts have held that a contractor has both an obligation to do the works, and a corresponding right to be able to do those works.
- Instructions after practical completion has already occurred.
Does the contractor have the right to carry out additional work?
A contract may give the employer the right to instruct additional work, but that does not mean there will be an implied term that if additional work is required, the employer must instruct the contractor to carry it out.
Can the contractor object to a variation?
This would depend on the terms of the relevant variation clause. However, the standard forms generally contain a limited right for the contractor to object. For example, JCT provides that a contractor may make a reasonable objection to an instruction that relates to the imposition by the employer of any restrictions regarding access, limitations of working space or working hours or the execution of work in a specific order.
Are there circumstances where an employer is obliged to instruct a variation?
Certain standard form contracts (such as the old ICE conditions) place a positive obligation on the engineer to instruct a variation if this was necessary for completion. However, whether such an obligation may be implied is more complex. There is a tension between the contractor’s obligation to build what is described in the contract even if that is impossible, and the implied duty on the employer to co-operate.
What if there is no variation clause?
All standard form construction contracts contain variation clauses, but what if the parties have contracted on, say, a simple agreement of price and scope of work without a variations clause?
First, there is no implied right for an employer to instruct a variation under a construction contract. Therefore if there is no express contractual right for an employer to instruct variations, the contractor can refuse to carry out such variations without consequence.
Second, if the contractor agrees to carry out such variation, this varied work may be construed as a new contract such that the varied work is valued on a different basis than under the original contract and not based on the rates and prices in that original contract.
Sponsor Licence Compliance: Key considerations & how to be audit ready
Join us for the third in our series of mini webinars on post Brexit immigration about sponsor licence compliance.
The Future of Property Careers
Join to our panel discussion and Q&A with industry leaders on the range of opportunities within the property and construction sector.
New tax on property developers - consultation paper published
The government published a consultation paper on the design of the new residential property developers tax.
Procuring modular housing: Is MMC becoming mainstream?
Is Modern Methods of Construction becoming mainstream? Read what it means for Development and Procurement here.
Dual class share structures: how do they work and what are the pros and cons?
Dual class share structures allow a shareholder, for example the founder, to retain voting control over a company.
Rupa Lakha quoted by Legal Week on the liberalisation of the Indian legal market
The proposed trade deal could be “the proper catalyst for liberalisation”.
Q&A: Talking the telecoms talk
Georgina Muskett and Jonathan Wills answer queries on Electronic Communications Code agreement.
Property Patter: Navigating the complexities of Pharmacy Property
Pharmacy property is a specialist area which contains many traps for the unwary.
COVID-19 Vaccination – can an employer make it compulsory for employees?
We review what legal issues to take into account when considering to make vaccination compulsory as an employer.
Linking ESG and Executive Pay
How does a business go about embedding a focus on strong ESG performance into the structures and culture of its organisation?
National Security and Investment Act granted Royal Assent
The Act establishes a new regime for the review of mergers, acquisitions and other transactions that could threaten national security.
Recent Trends In Firewall Legislation: BVI, Bermuda And Gibraltar
Charles Russell Speechlys advises Waverton on acquisition of Cornerstone Asset Management
Established in July 2010 and with offices in Edinburgh and Glasgow, Cornerstone offers wealth management and financial planning advice.
What do the new Debt Respite Scheme Regulations mean for Landlords and Tenants?
This will provide legal protection from creditors in the form of either a breathing space or a mental health crisis moratorium.
Charles Russell Speechlys promotes five to Partner
The promotions are effective 1 May 2021 and are accompanied by one Legal Director and 15 Senior Associate promotions.
Risk allocation in commercial leases: the High Court considers rent suspension, insurance and frustration arguments
Read our summary of the full judgement on the latest Covid arrears case.
Charles Russell Speechlys boosts private wealth offering with the hire of an international tax team
Robert Reymond will be joined at the firm by Leigh Nicoll, Emma Tyrrell and Oliver Cooper.
Rachel Warren quoted by Construction Law on the increasing pressure on the HSE over Covid deaths
The Health & Safety Executive is likely to face increasing pressure to take enforcement action where employees have died from Covid.
Proposed Takeover Code Amendments – Key Changes
The Consultation Paper has now been followed by a corresponding response paper which made certain modifications to the initial proposals.
Building Back Better: Future Gazing
What’s next for the hospitality industry post-pandemic?