The Gulf diplomatic dispute and construction claims - extensions of time
As Qatar continues its progresses towards the 2022 FIFA World Cup and the development strategy for the 2030 National Vision, the current diplomatic dispute occurring in the Gulf is impacting on many parties involved in construction projects occurring throughout the nation.
The question concerning many of these parties, whether consultants, contractors, sub-contractors, suppliers or employers, relates to claims and what relief, if any, the parties are entitled to under their respective contracts.
In this article, we will look at the Contractor’s right to an extension of time under the FIDIC suite of contracts where that extension of time has been caused by the late supply of goods being shipped to Qatar through the UAE.¹ Following the commencement of the diplomatic dispute, many Contractors have suffered delayed as a result of goods having to be shipped from the UAE to Oman before they could be transferred to a vessel that would deliver the goods onward to Qatar.
Clause 8.4(d) of the FIDIC Conditions of Contract for Construction 1999 (Red Book) and FIDIC Conditions of Contract for Plant and Design Build 1999 (Yellow Book) provides as follows:
The Contractor shall be entitled subject to Sub-Clause 20.1 [Contractor’s Claims] to an extension of the Time for Completion if and to the extent that completion for the purposes of Sub- Clause 10.1 [Taking Over the Works and Sections] is or will be delayed by any of the following causes:
(d) Unforeseeable shortages in the availability of personnel or Goods caused by epidemic or governmental actions”
On its face, it would certainly appear appropriate to deem the embargo against the shipping of goods from the UAE to Qatar as a government action, however to be sure that it is applicable, there are a few items to consider more carefully.
Firstly, is there a shortage in the ‘availability’ of Goods? This is not immediately definitive, as the goods are available and it is only the fact that the delivery route to get them to Qatar is now much slower than originally planned. Although the meaning of ‘available’ is not defined, it would however be reasonable to argue that the goods would only be deemed to be ‘available’ when they are able to be in the possession of the Contractor. Although the goods are literally ‘available’ somewhere in the world, the fact that they cannot be utilized by the Contractor for the purpose of the works is arguably the intent of the clause. Either way, if the Contractor is going to suffer a delay by procuring the Goods from another source, or waiting for them to be delivered through an alternative route the Contractor is being prevented from utilizing the goods.
Secondly, we can consider if the actions of the UAE government were “Unforeseeable”, which is defined in the FIDIC suite as being “not reasonably foreseeable by an experienced contractor by the date for submission of the Tender”.
Although foreign policy experts may have been able to foresee such dispute, it appears that very few anticipated the types of prohibitions that have been levied. It could therefore only be reasonable to deem such knowledge or foresight to be well out of the realm of even an ‘experienced’ Contractor.
Finally, it is important to consider what was known at the ‘Tender Date’. Even if a tender is submitted after the commencement of the diplomatic dispute, the parties may have expected the matter to have been resolved quite quickly.
It is safe to say that Contractors who did not account for these delays in tenders submitted after the commencement of the diplomatic dispute will have a more difficult case to make that such delays were ‘Unforeseeable’. However, this will depend greatly on the timing and specific circumstances of each case, and as a result, there may be a genuine case here for many Contractors who were delayed and denied an extension of time.
It is noted that the Conditions of Contract for EPC/Turnkey Projects 1999, (Silver Book) does not include an equivalent provision to clause 8.4(d) of the Yellow and Red Books. The Contractor therefore needs to look further into the terms to consider if any other sub-clause of the Silver Book gives the Contractor an entitlement to an extension of time.
Firstly, Contractors may expect clause 13.7 [Adjustment for Changes in Legislation] to provide some relief. However, this clause only relates to the “Laws of the Country”. Assuming the law of the country is Qatar then a change of laws in the UAE that prohibits a ship from travelling directly from the UAE to Qatar will not be relevant.
The Contractor may also consider Sub- Clause 17.4 [Consequences of Employer’s Risks]. However it is submitted that this sub-clause would likely fail on two key aspects. The diplomatic dispute does not directly fall within any of the items listed in 17.3. In addition, the delay of shipping goods would not amount to “loss or damage to the Works”.
Finally, the Contractor’s may look to the application of clause 19 [Force Majeure]². This may, on balance, be the Contractor’s best option. Unlike clause 8.4(d) of the Yellow and Red Books, Sub-Clause 19.1 does not include any direct reference to ‘government actions’. However, as the list of circumstances is ‘not limited’ to the items listed in 19.1(i)-(v), Force Majeure will apply if the Contractor can show that it was “prevented from performing any of his obligations under the Contract” by an exceptional circumstance that:
(a) was beyond the Contractor’s control;
(b) was unforeseeable³ before entering into the Contract;
(c) could not have been reasonably avoided or overcome; and
(d) is not attributable to either party.
This is a more difficult claim and has more hurdles to clear than clause 8.4(d) of the Yellow and Red Books. Each element noted above will need to be considered and addressed by the parties, particularly (b) where the critical date is the ‘date of the Contract’ rather than the ‘date of the Tender’, and (c) where the Contractor will need to justify why such goods could not be procured from another source who could deliver them directly to Qatar.
If the scenario is deemed to be an event of Force Majeure then the Contractor will be entitled to an extension of time under clause 19.4(b) [Consequences of Force Majeure] (and by extension 8.4(b)) if:
(a) the Contractor has complied Sub- Clause 19.2 [Notice of Force Majeure]
(b) the Contractor has suffered a delay as a consequence of the Force Majeure event.
In conclusion, there may be more than one way for Contractors impacted by the diplomatic dispute to claim an extension of time under FIDIC Contracts, or indeed contracts based on such principals and risk allocation. It is therefore important that these options are considered and analyzed as early as possible and all necessary notices are issued in accordance with the Contract in order to protect this entitlement to the extent possible. Failure to do so may limit the Contractor’s likelihood of success in obtaining such relief and consequently result in exposure to delay damages.
¹The Economist (Print edition – Middle East and Africa) reported on 19 October 2017, that prior to the diplomatic dispute, the port located in Jebel Ali of the UAE handled more than 85% of shipborne cargo destined for Qatar.
²This clause applies to the FIDIC Suite and is not only limited to the Silver Book.
³Note that this is not a reference to the term defined in the Contract.
TL4 Fire Starters
Join us for a Festive FIRE Starters evening ahead of FIRE Starters Global Summit with our expert panellists.
Women in Chancery Christmas Celebration
Join us to celebrate the festive season and discuss the busy year we have had.
Alexia Egger Castillo
Inheritance contracts: An unknown planning tool for Brits with assets in Switzerland?
How you choose to dispose of your estate after death requires careful consideration, especially where assets are in multiple jurisdictions
FT Ignites Europe quotes William Garner on the FCA's approach to founder-led firms
"Taking a very strict line on founder-led firms risks undermining the FCA's competition mandate..."
Paula Boast is interviewed by Construction Week on Bahrain's construction industry and how it is moving towards more functional and responsible building
Dissecting Bahrain's construction practices
HR Magazine quotes Nick Hurley on redundancy and employee rights
"Unfortunately the legal remedies for employees in companies that become insolvent are very limited"
Construction News quotes David Savage on the slight rise in construction output in September
"It remains to be seen how the sector reacted in October amid the political turmoil"
How final is a Final Certificate?
A recent Scottish case grappled with the complexities of a smash and grab adjudication.
Court of Appeal decides defective notice to quit not saved by 'Mannai' principles
The Court of Appeal handed down judgment in the second appeal in O G Thomas Amaethyddiath v Turner & Ors  EWCA Civ 1446.
Charles Russell Speechlys wins Best Legal Services: Private Equity – Pan – Africa at the AGF Service Providers Awards 2022
Best Legal Services: Private Equity – Pan – Africa at the AGF Service Providers Awards 2022
Sarah Jane Boon
The Independent quotes Sarah Jane Boon on the 9.6% divorce increase in 2021
ONS statistics - Divorces in England and Wales: 2021
CDR – Essential Intelligence: The Belt and Road Initiative
Of the BRI nations situated within the Gulf, the UAE stands to be a leader and consolidate itself as the trade hub of the Middle East.
Jurisdictional Challenges in Arbitrations in Qatar
Exploring jurisdictional challenges in arbitrations within the State of Qatar, both under Qatar law and the law of the QFC.
Non-payment: What’s a Contractor to do?
Payments to contractors are widely subjected to extensive delays.
JCT v NEC: Which contract is right for your project?
Unsure of what building contact to use. Learn the difference between NEC and JCT contracts with our guide.
Michael Powner and Ellen Roberts write for People Management on the benefits and drawbacks of novel compensation packages
The benefits and drawbacks of novel compensation packages
Henry Cuthbert writes for Law in Sport on Usain Bolt's move to trademark his legendary victory celebration
Trademarked For Success – What Can Athletes Learn From Usain Bolt’s Legendary Victory Celebration?
Q&A: Code rights queries answered
Samuel Lear and Jonathan Wills field Telecoms Code questions in the light of a recent Supreme Court decision.
Charles Russell Speechlys advises Sage on sponsorship deals
Charles Russell Speechlys has advised Sage, a global leader in software technology, on a series of high-profile partnership deals
Private Equity News quotes Darren Bailey on the Americanisation of UK football
“We’re seeing an Americanisation where the matchday is turning into much more of an entertainment beyond just the sporting spectacle”