Split EPC Contracts: half the contract, double the risk?
What is a Split EPC Contract?
As the name suggests, a split engineering, procurement and construction (EPC) contract is a standard EPC contract which has been split between “onshore elements" and “offshore elements”. The “onshore” elements are undertaken by a local contracting entity that sits in the same group of companies as the contractor registered in an offshore jurisdiction undertaking the “offshore” elements. The majority of split EPC contracts are negotiated and then split rather than drafted for this purpose.
Typically, the offshore contractor takes responsibility for the design and engineering services and procurement of materials and equipment, with the onshore contractor taking responsibility for the construction works, local supply of materials and equipment, testing and commissioning and the remedying of defects.
The extent to which the offshore and onshore contracts can cross-refer to each other, i.e. to clarify the split of responsibilities or include a shared cap on delay damages based on the overall project price, is dictated by local tax legislation and disclosure requirements. In most jurisdictions only minimal cross referral is possible and there will inevitably be some gaps which cannot be closed without the structure unravelling. The parties will enter into an “umbrella agreement” in an attempt to get the risk profile of the split contracts as close as possible to a single EPC contract. The umbrella agreement would be between the employer and the two contractors and possibly a guarantor for the contractors. Given that the umbrella agreement is more akin to a guarantee, it is not always possible for it to contain strict obligations, so risks may be covered off by way of indemnities. This creates the obligation to make good a loss, rather than to prevent the loss in the first place, which is not as strong a position contractually as having single point responsibility.
During the performance of an EPC contract, contractors are exposed to a wide range of onshore taxes, including import and export duties, VAT, tax on its profits, property tax and withholding tax. In splitting the contract, the contractor’s exposure to local taxes fees and charges is limited and in principle should result in cost savings which ultimately should flow back to the employer in the form of a lower project cost.
Parties may also seek to split an EPC contract where currency exchange controls are in place which prevents a contractor from repatriating profit without losing a large proportion to currency exchange fees. If the majority of the contract price is payable offshore then local currency restrictions will not apply.
International energy projects lend themselves to this type of structure as a large component of their costs are in sophisticated plant and materials and specialist equipment, which are procured offshore. However, we are seeing this structure spread to construction projects in other industries. Those new to the concept will need to be alert to the following considerations.
The jurisdiction is likely to dictate exactly how the works and services will need to be split. Any gaps in the works to be carried out are likely to manifest themselves in the scope, with the potential for neither contractor to be responsible for parts of the works.
Parties can reduce this risk by giving one contractor responsibility for “sweeping up” any missing works.
This can be dealt with in the contracts or the umbrella agreement, as appropriate. In some jurisdictions it may be possible to have one scope of works which the contractors are jointly and severally liable for under the umbrella agreement, but in other jurisdictions this could cause the contracts to be seen as interrelated, which may incur local taxes on the whole project and as a result splitting the contract may not be commercially viable.
As the contractor parties are in principle controlled by the same entity, consideration should be given as to how delays under one contract which have an impact on the other contract should be dealt with. We would suggest that contractor delays under one contract should expressly not permit the contractor under the other contract to claim an extension of time. Similarly, any entitlement to time and money under either contract should not be applicable where the entitlement has arisen due to a breach or omission by the other contractor.
Limitations of Liability
In the majority of split EPC contracts, the split will be heavily weighted offshore, drastically reducing the potential liability of the onshore contractor. Consideration should be given as to whether caps on liability or delay damages should be by reference to a fixed value or a percentage of the project price, rather than a percentage of the onshore or offshore contract prices, and how these should be implemented.
Parties should consider which contractor is best placed to deal with any defects in materials, plant or workmanship, which contractor will have primary responsibility for testing and commissioning and whether representatives of both contractors will need to be present at tests and inspections.
Consideration should be given as to whether there should be a mutual contract termination clause so that a termination event under one contract would entitle the terminating party to automatically terminate the other contract. There may well be circumstances where the terminating party may not wish to terminate the other contract. The parties should agree at the outset what the consequences of such termination should be under both contracts.
Indemnities are likely to be a key feature of an umbrella agreement. There may be risks which cannot be covered off fully, so the contractors or the guarantor might agree to indemnify the employer for the loss it incurs as a result of the split structure, for example where a contractor benefits from the breach of the other contractor. There may also be situations where the employer agrees to indemnify the contractors.
Cross Set-Off Clauses
With single point responsibility, if a claim arises, employers are usually able to withhold sums due to a contractor rather than having to seek payment. In a split structure, the payment under the offshore contract is often frontloaded in comparison to the project programme. As such, a defect in the design may be discovered but the employer has no payments due to the offshore contractor on which to withhold sums. The parties could consider including a cross-set off clause to give the employer the ability to withhold sums due to the onshore contractor, instead of seeking a payment from the offshore contractor.
The parties should ensure the dispute resolution mechanisms in both contracts and the umbrella guarantee are aligned. They may also want to allow for consolidation so that any disputes can deal with all three contracts together, as one project.
The Future of Property Careers
Join to our panel discussion and Q&A with industry leaders on the range of opportunities within the property and construction sector.
LIDW21: A view from London and India - How dispute avoidance can keep construction and infrastructure plans on track
Join us as we discuss the challenges of the possible rise in disputes in the construction and infrastructure sector in India
Procuring modular housing: Is MMC becoming mainstream?
Is Modern Methods of Construction becoming mainstream? Read what it means for Development and Procurement here.
Dual class share structures: how do they work and what are the pros and cons?
Dual class share structures allow a shareholder, for example the founder, to retain voting control over a company.
Q&A: Talking the telecoms talk
Georgina Muskett and Jonathan Wills answer queries on Electronic Communications Code agreement.
Property Patter: Navigating the complexities of Pharmacy Property
Pharmacy property is a specialist area which contains many traps for the unwary.
COVID-19 Vaccination – can an employer make it compulsory for employees?
We review what legal issues to take into account when considering to make vaccination compulsory as an employer.
Linking ESG and Executive Pay
How does a business go about embedding a focus on strong ESG performance into the structures and culture of its organisation?
National Security and Investment Act granted Royal Assent
The Act establishes a new regime for the review of mergers, acquisitions and other transactions that could threaten national security.
Recent Trends In Firewall Legislation: BVI, Bermuda And Gibraltar
Charles Russell Speechlys advises Waverton on acquisition of Cornerstone Asset Management
Established in July 2010 and with offices in Edinburgh and Glasgow, Cornerstone offers wealth management and financial planning advice.
What do the new Debt Respite Scheme Regulations mean for Landlords and Tenants?
This will provide legal protection from creditors in the form of either a breathing space or a mental health crisis moratorium.
Charles Russell Speechlys promotes five to Partner
The promotions are effective 1 May 2021 and are accompanied by one Legal Director and 15 Senior Associate promotions.
Risk allocation in commercial leases: the High Court considers rent suspension, insurance and frustration arguments
Read our summary of the full judgement on the latest Covid arrears case.
Charles Russell Speechlys boosts private wealth offering with the hire of an international tax team
Robert Reymond will be joined at the firm by Leigh Nicoll, Emma Tyrrell and Oliver Cooper.
Proposed Takeover Code Amendments – Key Changes
The Consultation Paper has now been followed by a corresponding response paper which made certain modifications to the initial proposals.
Building Back Better: Future Gazing
What’s next for the hospitality industry post-pandemic?
Building Back Better: Re-examining your proposition
Why hospitality businesses should re-examine their proposition now
Building Back Better: Real Estate and Restructuring
How and why should hospitality businesses re-structure post pandemic?
Charles Russell Speechlys advises Fudco Partnership on sale to Exponent-backed Vibrant Foods
Fudco is a family-owned business selling South Asian ethnic foods in UK and Europe.