Liquidated damages: when are they penalties?
As many readers will be aware, the law on liquidated damages was recently changed in the Supreme Court decision in Cavendish Square v Makdessi. In GPP Big Field LLP v Solar EPC Solutions SL, we have seen one of the first applications of this decision to a construction contract.
GPP engaged Prosolia to construct five solar power plants across the UK under five separate EPC contracts. Four of these contracts included guarantees by Solar EPC Solutions SL, Prosolia’s Spanish parent company. Prosolia failed to complete the various projects by the required completion dates and subsequently became insolvent.
GPP claimed against Solar under its guarantees. The case raised a number of issues but we are going to concentrate on the claims for liquidated damages.
Solar argued that the liquidated damages clauses were penalties and therefore unenforceable because:
- They were expressly described as a “penalty”. Clause 21.5 read that: “In the event of the delay of more than fifteen (15) calendar days for the date of commissioning the Contractor shall pay to the [Employer] a penalty… The maximum of the penalty for delays to the Works shall be two hundred and fifty thousand pounds sterling per MWp (£250,000/MWp)”.
- The five EPC contracts provided the same “penalty” of £500 per day per MWp, despite the fact that each of the solar energy plants would generate different amounts of energy. Solar therefore argued that the pre-determined sum could not be based on a genuine pre-estimate of GPP’s losses.
Solar also argued that as one of the contracts had been terminated, the liquidated damages clause did not survive the termination of that contract.
The Court held that the liquidated damages clauses were not penalties, and were therefore enforceable, for these reasons:
- Liquidated damages provisions for delay are common in construction contracts and GPP and Prosolia were experienced commercial parties of equal bargaining power able to assess the commercial implications of such clauses.
- It is in the nature of liquidated damages clauses that they are often used when precise prediction of the likely loss is difficult. They are therefore often expressed in round figures.
- The fact that the loss resulting from the breach may vary in amount depending on the actual circumstances at the time does not of itself give rise to any inference that the sum agreed is a penalty, provided it is not extravagant and unconscionable in comparison with the greatest loss that might have been expected, at the time the contract was made, to follow from the relevant breach.
- Ultimately, the sum specified did not exceed a genuine attempt to estimate in advance the loss which GPP would be likely to suffer from the relevant breach. It was not in any way extravagant or unconscionable in comparison to GPP's legitimate interest in ensuring the project was ready on time.
- The references to “penalty” in the clause were only “equivocal indications”, it was the substance of the matter that was relevant. The Court also held that the liquidated damages provisions survived the termination of the contract.
The Court relied on the earlier decision of Hall v Van Der Heiden (No 2) where the Court had held that a liquidated damages clause would survive the termination of the contract as a “matter of principle” because otherwise this would reward the defendant for their own default.
The Court’s decision that these provisions were not a penalty was perhaps not overly surprising, as it is rare for liquidated damages provisions in construction contracts to be held unenforceable as a penalty. This decision does show that, following Makdessi, whether the liquidated damages was a genuine pre-estimate of loss is still an important aspect of whether the provisions are a penalty. However, the Court will ultimately apply the test in Makdessi of whether the sum stipulated is exorbitant or unconscionable having regard to the innocent party’s interest in the performance of the contract.
The decision that liquidated damages would survive termination is more surprising. A common view is that liquidated damages should not be payable after termination, as in these circumstances the contractor loses control of the eventual time of completion. Instead, the contractor should be liable for the losses incurred by the employer as a result of the termination of the construction contract, including the losses it has incurred as a result of any delay in the completion of the works. In such circumstances, the contractor would not be “rewarded” for their own default if liquidated damages did not survive termination, instead the employer would be under a duty to mitigate its loss and to then prove the actual loss it had incurred.
IBA Annual Conference
The IBA heads to Miami for its 2022 Annual Conference bringing together thousands hundreds of lawyers from around the world.
Joint Venture Opportunities
Join our panel where we will discuss various topics including Joint Venture structuring and Partner procurement.
FT Wealth quotes Sarah Anticoni on forum shopping
"Being the first to file for divorce is not a foolproof way of securing an English hearing"
What can UK investors interested in Life Sciences learn from their more experienced, including US, counterparts?
The recent tie-up between Canary Wharf and Kadans demonstrates the enthusiasm to access the lucrative UK life sciences market.
Helen Coward writes for Tax Journal on the main purpose test for SDLT group relief
Mainly ignored? The main purpose test for SDLT group relief
The Ayes have it - Collateral Warranties can be a ‘Construction Contract’
The Court of Appeal handed down its judgment in the case of Abbey Healthcare (Mill Hill) Limited v Simply Construct (UK) LLP
Charles Russell Speechlys advising Battery Ventures on the sale of SPT Labtech for £650 million.
Battery Ventures has raised over $9 billion to invest in software and services, enterprise infrastructure, and much more around the world.
Windrush Day 2022 – supporting access to justice
Charles Russell Speechlys is proud to continue supporting survivors of the Windrush scandal in their fight for justice.
The Leasehold Reform (Ground Rent) Act 2022: Landlords and developers beware serious sanctions for non-compliance
The Leasehold Reform (Ground Rent) Act 2022 received Royal Assent on 8 February 2022 and will come into force on 30 June 2022.
Charles Russell Speechlys has advised long-standing client Stonegate on a series A investment into Peckwater Brands
Stonegate is one of the largest pub companies in the UK with a rich portfolio that covers over 4,500 sites.
Pro bono support for major office premises move for charity in Stoke-on-Trent
Emmaus entities provide safe homes, community support and meaningful work to formerly homeless people across the UK.
Financier Worldwide quotes Rachel Warren on the UK’s Economic Crime Act
Evaluating the UK’s Economic Crime Act
Property Patter: Reasonable Endeavours
What does it mean to use ‘best’, ‘all’ or ‘reasonable’ endeavours?
The balance between Fairness and Certainty in UAE Construction Contracts
Articles 106 and 390(20) arguably make the UAE more focused on fairness than some of its counterparts in the GCC.
Could the UK’s Life Sciences Vision be restricted by its Immigration Policy?
We explore some of the visa options that may be open to businesses in the sector and their relative pros and cons.
Joshua Green writes for Spear's Magazine on Wagatha Christie’s lessons for HNWs
Wagatha Christie’s lessons for HNWs
Stephanie Bonnello writes for the Practical Law Dispute Resolution blog on witness evidence
When are witness summaries permitted instead of witness statements and when should material be struck out from a witness statement?
Emma Humphreys and Paul McCarthy write for Property Week on the new landlord digital ID checks
Emma Humphreys and Paul McCarthy write for Property Week on new landlord digital ID checks
Carolyn Davies and Oliver Park write for Property Week on the key property points in the Building Safety Act
The key property points in the Building Safety Act
Unexplained Wealth Orders & Trustees
Learn about Unexplained Wealth Orders, what they are, who can obtain them and the implications that exist for trustees.