Grove Developments v Balfour Beatty: Beware the 'end of time'
Employers and contractors frequently agree interim payments schedules under construction contracts. In the recent case of Grove Developments Limited v Balfour Beatty Regional Construction Limited, the Court considered whether the contractor could apply for further interim payments if the works extended beyond the dates set out in such a schedule.
Grove Developments engaged Balfour Beatty to design and build a hotel and serviced apartments adjoining the O2 arena for a contract sum of over £120m. The works began in July 2013 with an intended completion date of 22 July 2015. The parties agreed a schedule of 23 dates throughout the intended construction period on which valuations and interim payments would be made.
The works continued beyond 22 July 2015 and Balfour Beatty issued a further payment application for over £23m. The Court was asked to decide whether Balfour Beatty had a contractual right to make this interim application (or any subsequent application). This was particularly relevant as Balfour Beatty had commenced an adjudication seeking payment of the full sum claimed on the basis that no valid payment notice of payless notice had been served.
The Court held that parties may agree a schedule for interim payments which does not cover the whole period over which the works actually take place. Such a schedule would be compliant with the Construction Act. To interpret the Construction Act as requiring interim payments for all work under a construction contract lasting 45 days or more would be a draconian restriction on the freedom of commercial parties to contract on terms of their choosing.
The Court therefore found that as the parties had failed to reach an agreement to extend the payment schedule, Balfour Beatty had no contractual right to further interim payments.
It is common for parties to agree payment schedules that do not address what will happen if the works are extended beyond the expected completion date. This decision shows the dangers of this from a contractor’s perspective, as this could allow the employer to refuse to make further interim payments in the event of such delay. This could cause significant cashflow issues for contractors, especially when there is a long delay to the works. This is potentially very unfair for contractors if they are not responsible for such delay.
To avoid this, contractors should seek to include a mechanism in any such payment schedule that will set out the additional dates for interim payments if the works are extended. Such a mechanism could simply state that in the event of a delay beyond the expected completion date, further interim payments would be permitted on say the last working day of the month.
News & Insights
It's About Time!
A summary of the most frequently asked questions on time.
Reform of Retention
The use of retentions was thrust into the spotlight with the introduction of the Construction (Retention Deposit Schemes) Bill 2017-19.